Home
Forms Library
Subcontractor's Agreement - Arkansas

Subcontractor's Agreement - Arkansas 2025

Subcontractor's Agreement - Arkansas Preview on Page 1

See details

4.1 out of 5

57 votes

The document is a Subcontractor's Agreement outlining the terms and conditions between a Contractor and Subcontractor for a construction project. It details the responsibilities of both parties, including the scope of work, payment terms, scheduling, permits, and conditions for delays or additional work. The agreement emphasizes compliance with regulations, arbitration for disputes, and provisions for handling hazardous materials. It serves as the complete contract governing the relationship and obligations related to the project.

Here's how it works

01. Edit your form online

Type text, add images, blackout confidential details, add comments, highlights and more.

02. Sign it in a few clicks

Draw your signature, type it, upload its image, or use your mobile device as a signature pad.

03. Share your form with others

Send it via email, link, or fax. You can also download it, export it or print it out.

How to use or fill out Subcontractor's Agreement - Arkansas with our platform

Ease of Setup

DocHub User Ratings on G2

Ease of Use

DocHub User Ratings on G2

Click ‘Get Form’ to open the Subcontractor's Agreement in the editor.
Begin by filling in the Contractor and Subcontractor details, including names, addresses, and contact information. Ensure you specify whether the Subcontractor is an individual or a business entity.
Next, provide the Jobsite address and legal description. This section is crucial for identifying where the work will take place.
In the 'Description of Work' section, clearly outline the tasks and responsibilities of the Subcontractor. Reference any drawings or specifications that pertain to this work.
Fill in the estimated start date and completion date for the work. This helps set clear expectations for both parties.
Specify the subcontract price and payment schedule. Be sure to include any conditions related to change orders or late payments.
Review all terms and conditions carefully before signing. Make sure both parties understand their rights and obligations under this agreement.

Start using our platform today to streamline your document editing and signing process for free!

be ready to get more

Complete this form in 5 minutes or less

Get form

Got questions?

We have answers to the most popular questions from our customers. If you can't find an answer to your question, please contact us.

Does a subcontractor need a contract?

When you are looking at supply chain procurement, there are three types of subcontractor: Domestic Subcontractors. Nominated Subcontractors. Named Subcontractors.

What is a subcontractor agreement?

While a contract can be made orally, it is good practice to have a written contract in place before the subcontractor begins work. Contracts are generally bespoke to each project, said Julie, but as a bare minimum must conﬁrm scope of works, price, programme and payment.

What are the 3 factors that can determine if you are a subcontractor?

In determining the employment tax status of a worker, the IRS considers three categories of evidence: Behavioral control, Financial control, and Relationship of the parties.

What is required for subcontracting?

Main Requirements: (1) Registered Company; (2) BEE Affidavit; (3) ID Documents of Directors.

What should be in a subcontractor agreement?

Clearly define the scope of work, including drawings and specifications. Specify the contract price and payment terms. Include a detailed schedule for the subcontractors work. Address the flow-down of terms from the Prime Contract.

What needs to be in a subcontractor agreement?

Both sides need to agree on a start date, end date, and important milestones and due dates to track progress. A well-defined schedule helps manage the project efficiently and ensures that the subcontractor aligns with the projects timeline.

What paperwork do I need for a subcontractor?

W9 form. All subcontractors should be providing you with an IRS W9 form. This documentation lets you know the type of company the subcontractor is (corporation, LLC, sole proprietor, etc), as well as their tax identification number or Social Security number if they are an individual.

Subcontractor's Agreement - Arkansas 2025

Here's how it works