Home
Forms Library
Subcontractor's Agreement - Idaho

Subcontractor's Agreement - Idaho 2025

Subcontractor's Agreement - Idaho Preview on Page 1

See details

4.7 out of 5

50 votes

The document is a Subcontractor's Agreement outlining the terms and conditions between a Contractor and a Subcontractor for a construction project. It details the responsibilities of both parties, including the scope of work, payment terms, scheduling, permits, and conditions for delays or additional work. The agreement emphasizes compliance with regulations, arbitration for disputes, and provisions for handling hazardous materials. It serves as the complete contract governing the relationship and obligations related to the project.

Here's how it works

01. Edit your form online

Type text, add images, blackout confidential details, add comments, highlights and more.

02. Sign it in a few clicks

Draw your signature, type it, upload its image, or use your mobile device as a signature pad.

03. Share your form with others

Send it via email, link, or fax. You can also download it, export it or print it out.

How to use or fill out Subcontractor's Agreement - Idaho with our platform

Ease of Setup

DocHub User Ratings on G2

Ease of Use

DocHub User Ratings on G2

Click ‘Get Form’ to open the Subcontractor's Agreement - Idaho in the editor.
Begin by filling in the Contractor and Subcontractor details, including names, addresses, and contact information. Ensure you specify if the Subcontractor is an individual or a business entity.
Provide the Jobsite address and legal description. This section is crucial for identifying where the work will take place.
In the 'Description of Work' section, clearly outline the tasks and responsibilities of the Subcontractor. Reference any drawings or specifications that pertain to this work.
Fill in the estimated start date and completion date for the work. This helps set clear expectations for both parties.
Specify the subcontract price and payment schedule. Be sure to include any conditions related to change orders or late payments.
Review all terms and conditions carefully before signing. Make sure both parties understand their rights and obligations under this agreement.

Start using our platform today to streamline your document editing and signing process for free!

be ready to get more

Complete this form in 5 minutes or less

Get form

Got questions?

We have answers to the most popular questions from our customers. If you can't find an answer to your question, please contact us.

How much is a contractor license in Idaho?

The Idaho Contractors Board will verify the information on the contractor registration application and if it is in order, they will mail a certificate of registration and a wallet-sized card showing the registered contractors name and registration number, within a two or three weeks of receiving the application.

What should be in a subcontractor agreement?

The subcontractor agreement should identify the amount, timing, and conditions under which payments will be made, including any payments dependent upon achieving certain milestones, submission of specific documents, or receipt of payment by the general contractor.

Do I make a subcontractor a contract?

Without a solid agreement in place during construction projects, you risk misunderstandings, delays, and legal complications that can derail the things youre working on. This is why creating a clear subcontractor contract is a necessity so every party knows their responsibilities and expectations.

What are the different types of contractors licenses in Idaho?

It costs $50 to register as a contractor in Idaho, either as an individual or a business. Other trades in the construction industry may require additional licensing and fees.

Do subcontractors need a license in Idaho?

Similarly, if a contractor or subcontractor is involved with publicly funded construction projects, they must also be licensed. They can either get a public works contractor license or a construction manager license. More often, Idaho general contractors only need to register with the state.

Are contractors required to be licensed in Idaho?

While there are no general contractor licenses in Idaho, registration with the Idaho Bureau of Occupational Licenses (Idaho Contractors Board) is still required to conduct business. This also allows contractors to appear on the Idaho contractor license lookup list.

Does a subcontractor need a contract?

Top tips for taking on a subcontractor Ensure you have a written contract signed by each party clearly setting out their obligations. If possible, get it drafted or checked by a lawyer.

Subcontractor's Agreement - Idaho 2025

Here's how it works